Model Contract For Processing Contract

Processing contract model

The contractor is: the first, the second, the second, the second, the second, the second, the second, the right, the right.

Address: telephone, code, telephone, telephone, etc.

The legal representative is: post It's a very good one.

The ordering party: the first party, the first party, the third party, the second and the third.

Address: it is a very good one. Postal Code It's a very good one. Telephone It's a very good one.

The legal representative is: the position of the people's Republic of China.

The ordering party entrusts the contractor with the processing of the goods, and the contract is fully negotiated by both parties for the purpose of joint compliance.

The first processed product

Second quality requirements for finished products

Third methods and specifications, quantity and quality of raw materials

1. (the contractor completes the work with the Contractor's raw materials), the contractor must select the raw materials according to the contract and accept the inspection by the ordering party. If the contractor conceals the defects of the raw materials or does not affect the quality of the products in accordance with the raw materials that are not in conformity with the contract, the ordering party shall have the right to ask for rework, repair, reduction of the price or return of the goods.

2. (the consumption quota of raw materials should be specified clearly when the work is done with the raw material of the fixed party). The ordering party shall provide raw materials according to the time, quantity, quality and specifications stipulated in the contract. The raw materials supplied by the contractor to the ordering party shall be checked in time according to the contract stipulations. If the requirements do not meet the requirements, the ordering party shall be immediately changed or filled. The Contractor shall not replace the raw materials provided by the ordering party without changing parts.

3. the date calculation of raw materials and other articles submitted to (refer) shall be carried out in accordance with the seventh provisions.

Fourth ways to provide technical data and drawings

1. when the contractor is working in accordance with the requirements of the ordering party, he or she finds that the drawings or technical requirements are unreasonable, he shall notify the ordering party in time, and the ordering party shall reply within the prescribed time and make amendments. If the Contractor fails to get a reply within the prescribed time, he has the right to stop the work and notify the ordering party in time.

2. the Contractor shall strictly abide by the requirement of confidentiality for the work of the contractor, and shall not retain copies of the technical data without the permission of the ordering party.

3. the ordering party shall provide technical data and drawings according to the prescribed date.

Fifth price or gratuity.

The price or remuneration shall be carried out in accordance with the provisions of the state or competent authorities.

Sixth acceptance criteria and methods

1. according to the quality requirements, drawings and samples stipulated in the contract as acceptance criteria.

2. the ordering party shall check the work done by the contractor in accordance with the time limit stipulated in the contract. Before acceptance, the Contractor shall submit necessary technical data and relevant quality certificates to the ordering party. For a designated crop or item that is difficult to detect quality defects in short term inspection, the two sides shall negotiate and stipulate the guarantee period in the contract. In the guarantee period, the Contractor shall be responsible for repairing or returning the problem, except for the quality problems caused by the improper use and improper storage of the fixed party.

3. when the parties concerned have disputes over the quality of the contracted crops and items in the inspection, they may be provided by the statutory quality supervision and inspection institutions for inspection certificates.

Seventh time and place for delivery

1. the time limit for fixed crops shall be fulfilled in accordance with the provisions of the contract. If any party requests to advance or postpone the delivery of the designated crops, it shall reach an agreement with the other party in advance and execute it according to the agreement.

2. calculation of fixed crop date: the date that the carrier's own conveyance is delivered to the fixed crop is the date of the date of receipt by the fixed party; the entrusted transport department shall take the date of the stamp issued by the carrier department when transporting the crops, and the date of the pickup of the crop shall be based on the known date of the contract, but the contractor must leave the necessary time for the party to issue the prescribed crop notice, and the two parties shall make the same calculation according to the agreed method.

Eighth packaging requirements and cost burden

Ninth transport methods and cost burden

Tenth terms and duration of settlement

Eleventh other conventions

The twelfth Party's liability for breach of contract

(1) failing to deliver the crops according to the quality stipulated in the contract or completing the work, if the parties agree to make use of them, they should pay the price according to the quality and reduce the remuneration or the price. If they do not agree to make use of them, they should be responsible for dressing or exchanging them, and bear the responsibility for overdue delivery. After trimming or changing, they still do not meet the contract stipulations, and the ordering party has the right to refuse to accept the losses. The losses thus caused will be compensated by the contractor.

Two, the number of scheduled crops or completed work is less than that stipulated in the contract. If the ordering party still needs it, it should be made up according to the number, and the supplementary part should be handled according to the overdue delivery. If the part of the ordering party does not need to pay late or late, the Contractor shall compensate the contractor for the losses.

Three. If the crops are not packaged according to the contract regulations, they need to be repaired or repackaged. They should be responsible for the repair or repackaging, and bear the expenses paid accordingly. If the ordering party does not require rework or re packaging, the Contractor shall pay the value of the unqualified package less than the qualified package. The damage caused by the packaging does not conform to the stipulations of the contract, and the Contractor shall pay for the loss.

Four, overdue delivery of fixed crops (including repair, replacement, supplement, etc.), the liquidated damages shall be paid to the fixed party. If there is no specific stipulation in the contract, it shall be paid in accordance with the relevant provisions of the people's Bank of China on the deferred payment, and the liquidated damages shall be paid to the fixed party according to the total amount of the portion of the overdue delivery. In the case of compensation, 1/1000 of the total amount of the remuneration of the overdue part shall be liquidated for breach of the day.

The authorized party shall have the right to refuse to collect the crops prior to payment without the consent of the authorized party.

Five, if a crop cannot be delivered or can not be completed, it shall pay a penalty for failing to deliver the crop or the total value of the total portion of the work part (10% to 30%) or the total amount of the remuneration (20% to 60%).

Six. The designated crops delivered elsewhere are not in conformity with the contract stipulations, and shall be paid by the ordering party for safekeeping and maintenance when they are temporarily maintained by the authorized party.

Seven, a fixed crop for transporting or delivering goods, where the wrong arrival place or receiving unit is responsible for transporting to the designated place or receiving unit (person) in accordance with the contract stipulations, and shall bear the liability for overpayment of miscellaneous charges and overdue delivery of fixed crops.

Eight, due to improper safekeeping, the damage, loss and damage of the raw materials, equipment, packaging and other articles provided by the ordering party shall be paid for the losses caused by the ordering party.

Nine, failing to inspect the raw materials supplied by the ordering party in accordance with the stipulations and time limits stipulated in the contract, or failing to meet the requirements of the raw materials according to the inspection, and failing to notify the parties to change and fill the contract according to the time limit stipulated in the contract, the Contractor shall be responsible for the quality and quantity of the work.

Ten, arbitrarily change the parts or materials of the original material or repair provided by the ordering party, and the authorized party shall have the right to refuse to accept the contract, and the Contractor shall compensate the party for the losses caused thereby. If the ordering party asks for rework or re repair, it shall be processed according to the requirements of the ordering party and bear the liability for overdue delivery.

Thirteenth parties' liability for breach of contract

1. The amount, specification, quality, or design of crops determined by midway shall be compensated for the losses caused by the contractor.

Two, the abolition of a contract in the middle of a journey is a breach of contract for the contractor who provides the original village materials to the contractor and fails to perform part of the total value of the gross price (10% to 30% percentage points), and does not belong to the contractor who provides the raw materials, and the Contractor shall pay the penalty amount of the percentage of 20%% to 60%% of the gross remuneration paid by the contractor.

Three. Failure to provide raw materials, technical materials, packaging or other necessary work and preparation to the contractor in accordance with the time and requirements stipulated in the contract. The Contractor shall have the right to terminate the contract, and the Contractor shall compensate the contractor for the losses resulting from the contract. The Contractor shall not cancel the contract, unless the date of delivery of the fixed crop is postponed, the Contractor shall reimburse the contractor for the loss to be made.

Four. If the crops are fixed beyond the time limit stipulated in the contract, they shall also bear the actual custody and maintenance fees paid by the contractor in addition to the liquidated damages stipulated in the fifth paragraph of this article. If the ordering party fails to get a fixed crop over a period of 6 months, the Contractor shall have the right to sell the fixed crop, and the proceeds shall be returned to the given party after deducting the remuneration, keeping and maintenance costs. When the sale of the fixed crop is less than the remuneration, maintenance and maintenance, the ordering party shall also make up for the insufficient part; if the fixed crop can not be sold, it should compensate the contractor for the loss.

Five. If the payment exceeds the contract date, the liquidated damages shall be paid to the contractor in accordance with the relevant provisions of the people's Bank of China on delayed payment. If the fee is calculated, the penalty for breach of the contract shall be paid by 1/1000 of the total fee per day.

Six, for no reason to refuse to accept the fixed crops, it should compensate the contractor for the losses and the transportation department's fines.

Seven, change the delivery location or receiving unit (person), bear the cost of more expenses.

Fourteenth force majeure

Within the time limit stipulated in the contract, due to force majeure, crops or raw materials are damaged or lost, the contractor may be liable for breach of contract after obtaining lawful proof. If the occurrence occurs during the time of delayed acceptance or undue refusal, the Contractor shall bear the liability and compensate the contractor for the losses arising therefrom.

Handling of fifteenth disputes

When disputes arise in processing contract, the parties concerned should resolve it through consultation.

1., apply to arbitration organs for arbitration;

2., bring a suit in a people's court.

This contract shall come into force on the date of the date of execution of the contract. The contract shall be invalid after the execution of the contract. During the execution of the contract, the parties concerned shall not arbitrarily change or terminate the contract. If the contract is not completed, the two parties shall jointly negotiate and make supplementary provisions, and the supplementary provisions shall have the same force as this contract.

This contract is made in two originals, one for each party and the other for the contractor. The copy of the contract is in duplicate, and it shall be paid to each of the parties.

The ordering party: the first party, the first, the second and the third.

The delegates are: the people, the people, the people.

In the year of the year

The Contractor: the company is in charge of the company.

The delegates are: the people, the people, the people.

The year is full of years.